Effective Date: June 2026
Welcome to OKK Construction. By accessing and using our website, services or submitting inquiries through our platform, you agree to comply with and be bound by the following Terms & Conditions. Please read them carefully before using our website or engaging our services.
Acceptance of Terms
By accessing this website, you acknowledge that you have read, understood and agreed to these Terms & Conditions. If you do not agree with any part of these terms, you should discontinue use of the website.
Company Information
OKK Construction
House 10, Main Nazim-ud-din Road, F-6/1, Islamabad, Pakistan, 44000
Phone: +92 337-5477888
Email: info@okkconstruction.com
Services
OKK Construction provides residential and commercial construction services, including but not limited to:
- Luxury Home Construction
- Villa Construction
- Commercial Building Construction
- Turnkey Construction Solutions
- Grey Structure Construction
- Renovation & Remodeling
- Construction Planning & Project Management
All services are subject to project-specific agreements, quotations and contracts.
Quotations & Estimates
Any quote, estimate or proposal provided through our website, email, phone or consultation is for informational purposes only and may change based on project requirements, material costs, design modifications, site conditions and other relevant factors.
A final project cost will be determined through a formal agreement between the client and OKK Construction.
Client Responsibilities
Clients are responsible for:
- Providing accurate project information
- Obtaining any required approvals or permissions where applicable
- Reviewing project proposals and agreements before approval
- Making payments according to agreed schedules
- Communicating project requirements clearly and promptly
Payments
Payment terms, schedules and methods will be outlined in individual project agreements. Failure to make payments according to agreed terms may result in project delays, suspension of work or additional charges where applicable.
Intellectual Property
All content on this website, including text, images, graphics, logos, designs and other materials, is the property of OKK Construction unless otherwise stated.
No content may be copied, reproduced, distributed or used without prior written permission.
Website Use
You agree not to:
- Use the website for unlawful purposes
- Attempt to gain unauthorized access to website systems
- Submit false, misleading or fraudulent information
- Interfere with the functionality or security of the website
Limitation of Liability
While we strive to provide accurate information, OKK Construction does not guarantee that all website content is complete, current or error-free.
We shall not be liable for any direct, indirect, incidental or consequential damages resulting from the use of this website or reliance on its content.
Third-Party Links
Our website may contain links to third-party websites for informational purposes. OKK Construction is not responsible for the content, privacy practices or availability of external websites.
Project Timelines
Project timelines are estimates and may be affected by factors beyond our control, including weather conditions, material availability, regulatory approvals, labor availability and client-requested changes.
Reasonable delays shall not constitute a breach of contract.
Changes to Terms
OKK Construction reserves the right to update, modify or replace these Terms & Conditions at any time without prior notice. Updated versions will be posted on this page.
Governing Law
These Terms & Conditions shall be governed and interpreted in accordance with the laws of Pakistan. Any disputes arising from the use of this website or our services shall be subject to the jurisdiction of the courts of Pakistan.
Contact Us
For any questions regarding these Terms & Conditions, please contact:
OKK Construction
📞 +92 337-5477888
📍 House 10, Main Nazim-ud-din Road, F-6/1, Islamabad, Pakistan, 44000